1. The Defendant’s KRW 178,309,80 for the Plaintiff and 6% per annum from December 22, 2017 to May 3, 2019, and the following.

In fact, the Plaintiff and the Plaintiff Co., Ltd. mean the total contract amount of the annual construction work, such as the contract amount of KRW 829,000,000 and the total contract amount of the total construction period for long-term continuing construction work, etc., on December 18, 2015 with respect to the Defendant (Demand Agency: the National Biological Resource Center of the Ministry of Environment) and the Incheon Jinjin-gun C (hereinafter “instant construction work”).

4,123,80,000 won for construction, 540 days from December 21, 2015 to June 12, 2017, and 0.1% of the contract amount for delay compensation (hereinafter “instant construction contract”).

The instant construction project was implemented in a long-term continuing construction project, and the Plaintiff and the Defendant did not change the contract term of construction of the instant construction project on December 18, 2015 (the total construction period: 4,123,800,000) - No change in the total construction period of 20.7 days on July 31, 2016 (the total construction period: 20.7. 12. 1. 1. 1. 1. 2. 1. 1. 2. 2. 1. 2. 1. 2. 1. 2. 1. 2. 20: no change in the total construction period of the instant construction project (the total construction period: 4,123,800,00): No change in the total construction period of the 20. 27. 1. 27. 2016. 2. 27. 2016. 27. 2016. 207. 2. 207. 2. 2. 201. 201.