1. The Defendant’s KRW 23,00,000 as well as the Plaintiff’s annual rate of KRW 6% from December 5, 2014 to April 29, 2015.

1. Facts of recognition;

A. On December 3, 2014, the Plaintiff agreed to develop a setnet system and website within 60 days from the date the Defendant’s design confirmation became final and conclusive, but the first stage development work relating to the e welfare hall is completed by January 19, 2015, and the Plaintiff shall pay 23 million won, including the additional tax, to the Defendant.

(hereinafter “instant contract”). B.

Meanwhile, in addition to the above development services, the Plaintiff and the Defendant agreed in the instant contract that the Defendant shall maintain and repair the existing Plaintiff’s tronets including the computations to be developed by the Defendant for two years from January 1, 2015 to December 31, 2016, including the computations to be developed by the Defendant during the development period, including the server’s modification, inspection site, website, etc., and to pay KRW 700,000 per month to the Defendant at the cost of maintenance and repair.

(hereinafter referred to as “instant maintenance and repair services”) C. The Defendant’s service related to the said maintenance and repair.

On December 4, 2014, the Plaintiff paid KRW 23 million to the Defendant according to the instant contract. D.

On February 16, 2015, the Plaintiff filed a claim for compensation for delay with the content that “A person in charge of the Defendant did not take any measure for the confirmation of design due to retirement, omission of takeover of duties, etc., and the first stage development project related to the e welfare center did not take any measure until January 19, 2015, and that the e welfare center may not take any measure until January 21, 2015. On January 21, 2015, the Plaintiff continued to hold it until January 24 through 25, 2015.” As stipulated in the instant contract, the Plaintiff filed a claim for compensation for delay with a priority of KRW 1,275,750 in compensation for delay, and a claim for compensation for delay for all development periods until the integrated system can be filed later.”

E. On February 24, 2015, the Plaintiff concluded that “In accordance with Article 9(1) of the instant contract, the Plaintiff cancelled a setnet system and a new web site development contract as of February 28, 2015, and terminated the current Humannet system and web site maintenance contract.”