logobeta
본 영문본은 리걸엔진의 AI 번역 엔진으로 번역되었습니다. 수정이 필요한 부분이 있는 경우 피드백 부탁드립니다.
Text
Reasons
텍스트 조절
arrow
arrow
(영문) 전주지방법원 2020.05.21 2018가합2010
공사대금
Text

1. The Defendant’s KRW 2,587,190,210 as well as 5% per annum from January 13, 2018 to May 21, 2020, and the following.

Reasons

1. Basic facts

A. 1) The Plaintiff and B Co., Ltd. (hereinafter “B”).

(C) A corporation (hereinafter referred to as “C”)

The ratio of investment shall be 10%, B 80%, and C 10%, and the joint supply and demand organization with the representative company B (hereinafter referred to as the “joint supply and demand organization of this case”).

(2) On October 29, 2007, the instant joint contractor and the Defendant entered into a contract with the Defendant for construction work under a long-term long-term contract (hereinafter “instant construction contract”) with the Defendant for construction work (hereinafter “instant joint contractor”) with the total construction cost of KRW 1,00,00,00,000,000 for the total construction cost, KRW 60,556,562,000 for the total construction cost, and KRW 180,00 from the date of commencement of the construction period (from November 5, 2007 to May 3, 2008), and KRW 2,520 for the total construction period from the date of commencement of the construction period (hereinafter “instant construction contract”).

3) The general conditions of the construction contract applicable to the instant construction contract (hereinafter “general conditions”)

) 중 이 사건과 관련된 부분은 [별지 1] 일반조건 기재와 같다. 나. 이 사건 공사계약의 변경 구 분 차수 횟수 계약일 계약금액(천원) 공사기간 비고 착수일 준공일 기간 장기계속계약 1 최초 2007. 10. 29. 100,000,000 2007. 11. 5. 2008. 5. 3. 181 1 2007. 12. 18. 20,000,000 2007. 11. 5. 2007. 12. 31. 57 -124 2 최초 2008. 2. 18. 814,000,000 2008. 2. 22. 2009. 1. 22. 336 279 1 2008. 12. 22. 1,000,000,000 2008. 2. 22. 2009. 2. 16. 361 25 계속비계약 3 최초 2008. 12. 30. 63,937,400 2008. 12. 30. 2014. 9. 28. 2,099 1 2010. 12. 24. 66,954,500 2008. 12. 30. 2014. 9. 28. 2,099 2 2010. 12. 23. 67,560,500 2008. 12. 30. 2014. 9. 28. 2,099 3 2011. 10. 19. 67,560,500 2008. 12. 30. 2014. 9. 28. 2,099 4 2012. 5. 9. 67,560,500 2008. 12. 30. 2014. 9. 28. 2,099 5 2014. 5. 20. 70,632,500 2008. 12. 30. 2014. 9. 28. 2,099 6 2014. 5. 20. 71,578,500 2008. 12. 30. 2015. 12. 26. 2,553 1차 공기연장 ( 454일) 7 2015. 6. 23. 73,140,500 2008. 12. 30. 2017. 12. 15. 3,273 2차 공기연장 ( 720일 8 2015. 12. 22. 81,312,000 2008....

arrow