logobeta
본 영문본은 리걸엔진의 AI 번역 엔진으로 번역되었습니다. 수정이 필요한 부분이 있는 경우 피드백 부탁드립니다.
Text
Reasons
텍스트 조절
arrow
arrow
(영문) 울산지방법원 2020.09.10 2018가합20138
공사대금
Text

The defendant shall pay to the plaintiffs each money stated in the corresponding column of "request amount" in the attached list as well as from January 18, 2018.

Reasons

1. Basic facts

A. The Defendant entered into a contract for construction works between the Defendant and N Co., Ltd. (hereinafter “N”) around May 2016.

B) As between N and N, the Defendant’s construction of the building located in Ulsan Jung-gu O (hereinafter “instant construction”) and the building constructed by the instant construction is “the instant building.”

(1) The date of commencement of the construction project in Ulsan Metropolitan City, Jung-gu: The date of completion of the completion of the construction project on May 25, 2017: the contract amount on April 30, 2017: the sum of money KRW 8,700,000 (Won 8,700,000,000) - value-added tax shall be included.

(2) The N did not complete the instant construction by April 30, 2017, which is the deadline for completion stipulated in the said contract, and the Defendant and N entered into a modified contract with the following major contents (hereinafter “instant modified contract”). Around April 30, 2017, the Defendant and N did not complete the instant construction by April 30, 201, including (i) extension of the scheduled date of publication stipulated in the said contract; and (ii) change of the construction cost to be paid by N from the Defendant to KRW 7,77,77,00.

3. Date of commencement: October 5, 2016.

4. Date scheduled for completion: September 5, 2017.

5. Contract amount: The original amount of l.e., l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. g. g. 7,777,77 l. g. l. l. l. g. l. l. l. g. l. l. l. g. l. l. l. l. g. l. l. l. l. l. l. l. g. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l. l

9. Compensation rate for delay: Article 9 (Period of Commencement of Construction Works) (1) of the General Conditions for Standard Contract for Private Construction Works per day of delay and the date of completion thereof shall be the contract.

arrow