1. The defendant (appointed party) shall be 355,713,213 won, 237,142,142 won and each of the above.

1. Facts of recognition;

A. 1) The Public Procurement Service’s conclusion and content of the construction contract is a long-term continuing construction project (hereinafter “instant construction project”) upon the Defendant’s request.

A) The public notice of tender was given to the Plaintiff (Appointed Party; hereinafter “Plaintiff”).

) The Appointed B Co., Ltd. (hereinafter referred to as the “Appointed”), and the entry of the corporation, including the name of the party, is omitted.

A) Joint supply and demand contractors with a share of 60% (representative) and a share of 40% (hereinafter referred to as “joint supply and demand contractors of this case”).

2) On December 31, 2008, the instant joint supply and demand agreement was concluded with the Defendant and the construction cost of KRW 1,57,000,000, and the construction period from January 6, 2009 to November 5, 2009. The total construction cost of KRW 13,447,000,000, and the total construction completion date of January 6, 201.

3) From December 31, 2008 to October 31, 2017, the instant joint supply and demand agreement entered into several contracts with the Defendant on several occasions. Accordingly, the contract for the instant construction project was amended several times, including the total construction cost, the total construction period, etc., and the details of the amendment are as follows: (a) the instant joint supply and demand agreement entered in the following table (hereinafter referred to as the “number of contracts”); (b) the construction works by the relevant number of vehicles are called as the “number of vehicles”; (c) the construction works by the relevant number of vehicles are called as the “number of vehicles,” and (d) the overall contract and the instant contract, collectively, shall be called the “instant contract”.

A) Total contract amount on the date of completion of the contract period by the number of teas as of the division date (the first day of the ground for the ground for the ground for the ground for the ground) (the first time from January 6, 2009 to November 5, 2009 to November 6, 201, 13,447,000,000 one time as of November 6, 201, as of November 5, 2009 to December 6, 2009, as of November 6, 2009 to February 20, 201, the construction delay was changed on the same ground for the ground for the ground for the ground for the ground for the ground for the ground for the ground for the first time).