logobeta
본 영문본은 리걸엔진의 AI 번역 엔진으로 번역되었습니다. 수정이 필요한 부분이 있는 경우 피드백 부탁드립니다.
Text
Reasons
텍스트 조절
arrow
arrow
(영문) 광주고등법원(전주) 2020.05.07 2019나10205
공사대금
Text

1. The Intervenor’s motion for the Intervenor’s participation is permitted.

2. Of the judgments of the first instance court, the following payments shall be ordered:

Reasons

1. Basic facts

A. Upon entering into and amending the instant contract, the Defendant: (a) installed the installation of an excellent storage facility (hereinafter referred to as “the excellent storage facility of this case”); and (b) installed the said construction on the ground of the Kim Jong-si’s ground.

On December 5, 2012, the Plaintiff was awarded a contract for the instant construction project with the Defendant for the instant construction project, and the bid price was KRW 11,671,00,000 for the total construction period, and KRW 11,671,00 for the instant construction project. 2) On December 26, 2012, the Plaintiff entered into the first construction contract, which was a contract for each type of contract for the instant long-term contract, including the contract price of KRW 3,681,393,60 for the instant construction project, KRW 0.1% of the contract price for delay, and KRW 0.1% of the contract price for delay, and the construction period from December 27, 2012 to October 22, 2013 (after this period, changed to December 2, 2013). The total construction period was 7,537,781,000,000 for the instant construction project from December 28, 2012>

(3) The Plaintiff and the Defendant concluded a three-dimensional long-term contract between the Plaintiff and the Defendant by the third-party contract under the above long-term contract (hereinafter “the instant contract”). The main contents of the instant contract are as follows, and are as follows: the total completion date after the final amendment is set at KRW 8,083,250,00. The total completion date is set at KRW 8,083,250. 30. 2. 3. 18. 26. 18. 3. 20, 206. 3. 4. 2. 18. 2. 20, 206. 3. 3. 18. 2. 1. 20, 206. 3. 4. 1. 3. 2. 20, 2014. 3. 18. 2. 2. 18. 2. 2. 18. 2014

B. The major execution of the instant construction project was conducted as follows.

The commencement of construction works on December 27, 2012.

arrow