Text
1. The Defendant’s KRW 101,155,356 for the Plaintiff and the following: 6% per annum from October 13, 2018 to January 23, 2020;
Reasons
. It has become impossible.
With respect to the instant construction project, the notice of the seizure of claims that occurred at the Defendant’s other site was received to the Plaintiff, but there are many factors that may be at the site without resolution.
I think that I will submit a written waiver of construction work.
I, as the circumstances of the defendant, waive the case of the construction of this case, and do not raise any objection to this case.
On February 26, 2018, the Defendant, on May 3, 2018, drawn up a construction period assurance (Evidence A 4) with the following content to the Plaintiff.
* A construction period assurance note * A wall, stairs, slves, slives of the first floor on April 30, 2018, the walls, stairs, slves, and slives on May 15, 2018, the 3rd floor walls, stairs, slabs, slves on May 30, 2018, the 15th floor 1, 2018, the 3, 4 slves, the 5 slives, the 5th floor on June 23, 2018, the 36th 0.6th 208th 36.6th 208.6th 208.6th 36.6th 206.6th 208.6th 2018.
I undertake to complete the release of the material.
* purely reinforced concrete process and delay due to natural disasters and other processes should, in principle, be done after consultation.
* It is promising that the responsibility for delay of construction due to material and supply and demand of human resources during construction will be the defendant, and will accept the requirements of the Administration due to delay.
The date of preparation: May 3, 2018: The Plaintiff and the Defendant: (a) the Plaintiff and the Defendant: (b) the construction period of the instant construction works on June 25, 2018: (c) the completion of construction: (d) the standard contract for construction works (amended by Ordinance of the Ministry of Strategy and Finance) (amended by Ordinance of the Ministry of Strategy and Finance) as of August 30, 2018; and (d) the main contents are as follows:
Plaintiff B: Details of construction work under Article 1
3. 1) Commencement of construction period: Completion of construction on December 1, 2017: August 30, 2018.