1. The defendant's KRW 5,616,263,172 and the above money to the plaintiff

A. From April 6, 2013 to May 2013, 2013, for KRW 5,005,675,215

1. Basic facts

(a) The name of a contracting body and a contract for construction works: The construction period of Section 5 of the Section for the Construction of the Section for the Facilities of the Section for the Section of the Section for the Section of the Section for the Section of the Section for the Section (the first year 2009): 14,872,828,000 in Seo-gu Incheon Metropolitan Government: the total construction period of KRW 175 days (from June 30, 2009 to December 21, 2009) from the date of commencement: the total construction period of KRW 175 days from the date of commencement (from June 30, 2009 to December 31, 201): the rate of liquidated damages for 915 days from the date of commencement (from June 30, 209 to December 31, 201): the Plaintiff, the Defendant, the Newdong Construction Co.,, Ltd., the Construction, the effective construction, the Construction of Korea Development Co., Ltd., the joint venture (hereinafter referred to as “joint”).

On June 30, 2009, the Korea Water Resources Corporation (hereinafter referred to as the “instant construction”) shall be organized, and on June 30, 2009, the five tools and facilities construction from the border canals.

2) After having been awarded a contract with the following contents, the construction period and the construction amount of the instant construction have been changed several times, and the total construction amount has been finally determined by December 6, 2012.

3 The ratio of investment by the joint contractors of this case shall be as follows, and the plaintiff becomes the representative of the joint contractors:

Plaintiff 30.9%, Defendant 24%, New East Asia Construction Co., Ltd., 4.7% Leeyang Construction Co., Ltd., 4.7% in total, 5% in total, 100% in total, 5% in Hanyang Construction Co., Ltd., Hanyang Construction Co., Ltd., Ltd.

B. The instant joint contractors completed construction works and remaining construction works. (1) On December 27, 2012, the instant joint contractors completed construction works and undergo a completion inspection. (2) Meanwhile, the instant joint contractors undertaken additional construction works until August 2013 by the date of completion inspection, such as the matters pointed out at the time of completion inspection and the request for transfer to a local government.

C. The plaintiff's financing execution and joint contractors' share 1) The plaintiff is the largest share holder and managing member of the joint contractors of this case (the main contractor of this case's construction work).