Text
1. The part against the defendant among the judgment of the court of first instance is revoked, and the plaintiff's primary claim corresponding to the above revoked part is revoked.
Reasons
1. The reasoning for this Court’s explanation concerning this part of the basic facts is the same as the corresponding part of the judgment of the court of the first instance, except in the following cases, and therefore, they are cited in accordance with the main sentence of Article 420 of
Attached Form
3 'The '111th (the next agreement, the first amendment, and the second amendment)' shall be added to "the date of completion/the reason for the change of payment" in "the column for the reasons for completion/the change of payment."
[Based on Recognition] The column adds “A evidence 15-1 to 4”.
2. The plaintiffs' claims
A. The instant construction contract was amended from December 8, 2009 to April 22, 2016 under the overall contract of the instant construction project, due to reasons not attributable to the Plaintiffs, such as lack of budget and delay of relocation. The Plaintiffs requested the Defendant to adjust the contract price pursuant to Article 23 of the General Conditions of the instant case on March 25, 2013; and on February 10, 2015 and April 19, 2016.
Therefore, from December 9, 2009 to April 22, 2016, which is the day following the original completion deadline under the overall contract of the instant construction project, the Defendant shall pay the Plaintiffs KRW 2,010,931,081 in proportion to the total amount of indirect labor expenses, expenses, general management expenses, profits, etc., which are the indirect construction expenses that the Plaintiffs additionally paid from April 22, 2016, and delay damages therefrom.
B. The expiration date of the total construction period, which was scheduled at the time of the initial contract for the instant construction project, was 1,440 days after the commencement of the construction work, namely, December 8, 2009, and the Plaintiffs were selected as the successful bidder after calculating the estimate based on the bill of quantity of bill prepared in accordance with the initial total construction period.
According to Article 3 (1) of the General Conditions of the Construction Contract of this case, the calculation sheet is.