1. The Defendant (Counterclaim Plaintiff) paid KRW 37,149,463 to the Plaintiff (Counterclaim Defendant) and its amount from September 11, 201 to April 8, 2015.

. The principal claim and counterclaim shall also be deemed to have been filed.

A. On July 8, 2010, the Plaintiff entered into a contract with the Defendant for a new construction of the Suwon-gu multi-family house C on the ground (hereinafter “instant house”) in Suwon-gu (hereinafter “instant construction contract”). The main contents are as follows.

Contract Amount: 423,00,000 additional taxes* Separate rate of liquidated damages for delay: 14.1.0 square meters excluded from total construction area of 40.2 square meters at 17.15 square meters at 40.2 square meters at 40.2 square meters at 23 square meters at 40.2 square meters at 20.3 square meters at 23 square meters at 23: 23.05 square meters at 23.05 square meters at 17.15 square at 40.2 square at 40.2 square at 40.2 square at 14.1 square at 14.0 square meters.

B. On May 13, 2010, prior to the conclusion of the instant construction contract, the Defendant was granted a construction permit with the following details, setting the instant house as Class II neighborhood living facilities and multi-family houses by the head of Suwon-si (hereinafter “the head of Jongno-si”).

A multi-family house (rooms) with 30.93 square meters in multi-family houses (households) with 22 square meters in multi-family houses (three households) with 131.93 square meters in multi-family houses (2 households) with 131.93 square meters in multi-family houses (2 households) with 131.93 square meters in a non-family house with an area for use by each floor, 12.24 square meters in a multi-family house with 85.17 square meters in a multi-family house (two households) with 131.93 square meters in a

C. On December 28, 2010, the Plaintiff completed the instant house in accordance with the aforementioned permission, and obtained approval for the use of the instant house on the same day, and around that time delivered the Defendant with the 2 and 3 floors of the instant house.

After obtaining approval for use as mentioned above, the Plaintiff completed a construction project to change the part of the first floor neighborhood living facilities into a house around February 25, 201 in accordance with the instant construction contract, and delivered the Defendant the part of the first floor among the instant housing on February 26, 2011. On September 9, 2011, the Plaintiff completed the construction project to extend the fourth floor around September 10, 201, and completed the construction project to the Defendant on September 10, 201.