beta
Text
1. All appeals filed by the plaintiffs and the claims filed by the plaintiff A, expanded in the trial, are dismissed.
2. Appeal;
Reasons
1. Basic facts
A. 1) On November 11, 2008, the Defendant: (a) a development project to develop the F-type of 857.541 square meters away from Chungcheongbuk-do as an E industrial complex (hereinafter “instant development project”); and (b) a development project to create a F-type of 857.541 square meters away from Chungcheongbuk-do as an E industrial complex.
(2) On February 3, 2009, the Defendant entered into a concession agreement with the D&C Global Co., Ltd. (hereinafter “D&C Global”) in order to promote the instant development project as a private development. On May 1, 2009, the Defendant obtained the project implementer of the instant development project from Chungcheongnam-do with the D&C Global.
(H) (Public Notice H. 3 of Chungcheongbuk-do) However, since D&C global failed to prepare the project fund, the implementation of the instant development project was delayed for a long period, and the defendant colored another private business entity. (2) On June 16, 2011, the plaintiff A submitted a letter of intent to participate in the instant development project to the defendant on June 16, 201, and the defendant submitted a letter of intent to participate in the project to the defendant on June 17, 2011, and on June 17, 2011, the defendant submitted a letter of intent to participate in the development project to the plaintiff "A, before the agreement, submitted the situation of securing funds to confirm the capacity to implement the instant development project (certificate of deposit with seal) before the agreement, ② deposit of KRW 1 billion in the performance bond of the instant development project (286,363,000,000,0000,000 won) with the defendant's prior notice and public notice of F.
2. In addition, the plaintiff A is obliged to pay the defendant the land compensation time when he is selected as the project operator and the payment period when it is possible to pay the defendant the land compensation time and several times, and the plaintiff A is the project operator.