1. The Defendant (Counterclaim Plaintiff) is jointly and severally liable to the Plaintiff (Counterclaim Defendant) for KRW 11,920,000 and its amount from November 7, 2013.

1. Basic facts

A. The Defendants are married couple, and around January 3, 2013, Defendant C completed each registration of transfer of ownership as to the size of 390 square meters in Gwangju City D, and Defendant B completed each registration of transfer of ownership as to the size of 371 square meters in the same Ri E.

B. On December 12, 2012, the Plaintiff entered into a contract for construction works with Defendant C and Gwangju-si, under which the Plaintiff would be awarded a contract for the construction of the construction of the multi-household building (hereinafter “non-Dong building”) on the land of Gwangju-si, with the content that it would be awarded a contract for the construction of the construction of the new construction of the multi-household building (hereinafter “non-Dong building”). On the same day, the Plaintiff entered into a contract for construction works with Defendant B to move the multi-household building into the land of Ri E (hereinafter “non-Dong building”) on the same day, including the above non-Dong building (hereinafter “each building of this case”). The contract for construction works

(2) Each construction contract for each building of this case is a construction contract for each building of this case. The scope of the construction project of the 4th floor above the ground (1.5 room, 1.5 room and 15 room after the completion of 2nd room) of the non-Dong Building ground (1.5 room, 3 room and 1.5 room room after the completion of 2nd room): All construction costs for civil engineering works, construction works, machinery works, electrical construction works, fire-fighting works, telecommunications works, and lighting works: 400,000 construction period for the 40,000 construction cost for the non-Dong building: Moving to the 5-month construction contract (the same building and non-Dong building are the same as the building and non-Dong building) or the person entrusted with the authority of the defendant (the construction supervisor) or the defendant (the construction supervisor) may request necessary measures in conformity with the contract and construction plan.

A civil petition that arises during the construction works of Article 9 (Civil Petitions) shall be resolved at the responsibility of the plaintiff.

Article 10 (Extension of Work Period) (1) In the event of delay in official works due to reasons not attributable to the Plaintiff, such as natural disasters and force majeure events, the Plaintiff may request the Defendants to extend the work period.

(2) When the defendant and the plaintiff agree on the grounds of special circumstances in the construction industry.