1. The Defendant’s KRW 33,480,00 for the Plaintiff and 6% per annum from November 22, 2014 to April 29, 2016.

1. Basic facts

A. The Plaintiff is a legal entity that manufactures and sells industrial machinery, and the Defendant is a legal entity that manufactures and sells steel facilities and exports and imports.

B. On February 15, 2012, the Defendant received an order from Nonparty Poco Construction to manufacture as a heating unit for construction at the port factories of Poco Construction. On February 15, 2012, the Defendant concluded a purchase contract with the Plaintiff on a set of KRW 198,00,000 (i.e., supply price of KRW 180,000,000, value added tax of KRW 18,000,000).

(hereinafter “instant contract”). C.

The delivery date determined by the Plaintiff and the Defendant when entering into the instant contract was May 15, 2012. However, Switzerland Construction, the ordering place, modified drawings necessary for the production of the instant goods several times and delayed overall fairness. Accordingly, the Plaintiff and the Defendant extended the delivery date to July 31, 2012 with the approval of Maco Construction.

Upon entering into the instant contract, the Plaintiff and the Defendant agreed to supply the Plaintiff parts, such as beeing and beeingber, among the parts necessary for the manufacture of the instant goods (such as the above, the part agreed to be directly supplied by the person who requested the manufacture of the goods) and the supply of private supplies to the Plaintiff was delayed.

In addition, as a result of the discovery of defects that are processed on the off-to-day seal, which are hard to use in accordance with the original purpose, in the private-class goods supplied by the Defendant to the Plaintiff, and the embarlinger has been processed differently from the off-to-day seal specifications, the whole process was delayed additionally.

E. The above C.

subsections and d.

circumstances such as the entry in the subsection.