1. Defendant B Co., Ltd.: (a) KRW 60,000,000 for the Plaintiff and the period from April 22, 2017 to October 26, 2018.

1. Basic facts

A. The Plaintiff and Defendant B (hereinafter “Defendant B”) entered into each of the instant contracts

) On January 12, 2012, the Republic of Korea (hereinafter referred to as the “instant land”) means the land E and four parcels, Chungcheongnam-gun, Chungcheongnam-gun, Chungcheongnam-do, and the same.

2) The construction of new apartment units (hereinafter referred to as “instant construction”)

As to the following contract agreement (hereinafter referred to as “instant contract”).

AB concluded the agreement.

1. A project owner: Defendant B;

2. The construction site: The land in this case;

4. Period of construction: From February 15, 2012 to September 30, 2012;

5. Contract amount: 3,400,000 won (excluding value-added tax).

6. Method of payment of the price: Quasi-special agreement;

7. The rate of liquidated damages: 1/1000 per day.

8. Warranty liability period: Matters stipulated under a two-year special agreement;

1. Scope of construction: Construction from the structural frame of the fourth floor constructed at the time of contract; lease shall include removal of retaining walls from each retaining wall of a building structure constructed after drawing modification to a unit apartment for sale;

2. The Plaintiff, Defendant B, and Defendant C Co., Ltd. (hereinafter “Defendant C”) are entitled to the payment of 20% advance payment of the construction cost as the payment of the construction cost, and the remainder payment within 10 days after the completion of the remainder payment.

(2) On December 25, 2012, with respect to the instant construction project, the following contract is deemed to be the “instant contract” (hereinafter “instant contract”) and the instant contract is collectively referred to as the “instant contract.”

AB concluded the agreement.

1. Construction name: F apartment construction;

2. The construction site: The land in this case;

3. Date of commencement: Within ten months from the commencement date of the relevant project to be completed on January 4, 2013.

5. Amount of the construction contract: 5,000,000 won (excluding value-added tax);

6. The payment method for the first payment - The payment method for the second payment: The payment shall be made after making a loan to the part of the part of the financial rights within one month after

- The second progress payment: The payment shall be made monthly in accordance with the construction progress rate, and the amount payable shall be paid in the right of sale in lots per household (5.3 million won per square year).

A contractor 1: Defendant B and contractor 2: The Plaintiff

B. The Plaintiff and G on January 2012 following the conclusion of the instant transfer contract.