1. The plaintiff (Counterclaim defendant)'s main lawsuit and the defendant (Counterclaim plaintiff)'s counterclaim are dismissed, respectively.

2. Due to the principal claim.

1. Facts of recognition;

(a) A contract agreement for construction works entered into between the original and the defendant;

3. Date of commencement: The scheduled completion date of May 20, 201: 600,000 won (including value-added tax) for the supply price of 6,600,000,000 won on March 30, 2012: 6,000,000 won: 6,000,000 won.

7. Division of contract amount (1) Division: 600,000,000 won (including value-added tax) for the first installment payment: 250,000,000 won (including value-added tax) for the second installment payment: 2,670,000 won for the second installment payment: 3,080,000 won for the second installment payment (including value-added tax): 3,000,000 won for the second installment payment: 3/100 for the second installment payment: 3/100 for the third installment payment: if there is any conflict between the standard contract for private construction works as of May 15, 201 and the contents of this contract, the contents of this contract shall prevail.

2. Determination on the subdivision of large substances: approximately KRW 40 square meters 15,000,000 = 600,000 officetels 600,000 = the aggregate of large substances of KRW 2,070,000 = 2,070,000 (including value-added tax under this Agreement) 1) Plaintiff on May 1, 2011, the Defendant and Chungcheong-si C-based neighborhood living facilities and officetels (hereinafter “instant building”).

) New construction works (hereinafter “instant construction works”)

2) As to the contract agreement (hereinafter “instant contract for construction”)

(2) Of the general conditions included in the instant construction contract, the contents of the instant construction contract are as follows.

Article 15 (Extension of Construction Period) (1) Where the performance of construction works is delayed due to a cause not attributable to the plaintiff, such as a cause attributable to the defendant, natural disaster, or force majeure, etc., the plaintiff may request in writing the defendant to extend the construction period.

(2) Upon receipt of a request to extend the contract period under paragraph (1), the defendant shall promptly investigate the fact and verify such fact, and take necessary measures, such as the extension of the contract period, so that the Corporation may appropriately implement it.

(3) The defendant shall be under paragraph (1).