1. The defendant shall pay 106,665,395 won to the plaintiff and 12% per annum from January 28, 2020 to the day of complete payment.

1. Indication of claims: To be as specified in attached Form 1;

2. Judgment without holding any pleadings (Articles 208 (3) 1 and 257 of the Civil Procedure Act);

3. The Plaintiff seeking damages for delay on KRW 106,665,395 for the remainder of the construction project from the day following the aggregate payment date. However, the Defendant’s obligation for the remainder of the construction project is an obligation for which the due date is not fixed and the due date for delay is the day following the date on which the claim for performance is filed. Thus, the Defendant’s obligation for the remainder of the construction project is the date following the day on which the copy of the instant complaint was served on the Defendant