logobeta
본 영문본은 리걸엔진의 AI 번역 엔진으로 번역되었습니다. 수정이 필요한 부분이 있는 경우 피드백 부탁드립니다.
Text
Reasons
텍스트 조절
arrow
arrow
(영문) 서울중앙지방법원 2021.01.13 2019가합42066
공사대금
Text

1. As to each of the Plaintiffs’ KRW 670,530,108 and each of them, the Defendant shall start on July 18, 2017, and each of them shall be KRW 100,000,000.

Reasons

1. Facts of recognition;

A. On April 2012, the Public Procurement Service issued a public notice of bid for the instant construction project by setting the 69,526,345,000 won in the estimated construction amount, and the construction period of 1,095 days in relation to the construction of roads from Busan Northern-gu to D (hereinafter “instant construction project”).

2) The Plaintiffs organized a joint supply and demand entity with a share of 50% by representing and investing in Plaintiff A Co., Ltd. (hereinafter “Plaintiff A”), and participated in the instant construction project tender, and were selected as a successful bidder.

B. On July 4, 2012, the instant joint water supply company entered into a contract for construction works with the Public Procurement Service on the basis of an additional total construction amount of KRW 37,203,410,200 with respect to the instant construction works, and the total construction date of July 10, 2012 as of July 9, 2015 (the total construction period of KRW 1,095).

구분 계약 체결 ( 변경) 일 공사기간 계약금액( 원) 비고 차수 변경 총괄계약 최초 2012. 7. 4. 2012. 7. 10. ~ 2015. 7. 9. 37,203,410,200 1회 2014. 12. 4. 2012. 7. 10. ~ 2017. 7. 30. “ 2회 2015. 12. 17. 2012. 7. 10. ~ 2017. 7. 30. 47,041,863,000 3회 2016. 12. 27. 2012. 7. 10. ~ 2017. 7. 30. 55,730,675,000 4회 2017. 3. 9, 2012. 7. 10. ~ 2018. 6. 10. “ 5회 2017. 12. 29. 2012. 7. 10. ~ 2018. 9. 17. 60,708,945,000 6회 2018. 9. 5. 2012. 7. 10. ~ 2018. 9. 17. 65,650,937,000 7회 2018. 9. 14. 2012. 7. 10. ~ 2018. 11. 16. “ 8회 2018. 11. 13. 2012. 7. 10. ~ 2018. 11. 30. “ 9회 2018. 11. 30 2012. 7. 10. ~ 2018. 11. 30. 66,785,771,000 10회 2018. 12 .21 2012. 7. 10. ~ 2018. 11. 30. 66,765,820,000 1 차수 최초 2012. 7. 4. 2012. 7. 10. ~ 2013. 9. 7. 21,000,000,000 1회 2013. 7. 16. 2012. 7. 10. ~ 2014. 6. 9. “ 기간 연장 2회 2014. 6. 9. 2012. 7. 10. ~ 2014. 12. 4. “ 기간 연장 3회 2014. 12. 4. 2012. 7. 10. ~ 2015. 9. 29. “ 기간 연장 4회...

arrow