logobeta
본 영문본은 리걸엔진의 AI 번역 엔진으로 번역되었습니다. 수정이 필요한 부분이 있는 경우 피드백 부탁드립니다.
Text
Reasons
텍스트 조절
arrow
arrow
(영문) 대구지방법원 김천지원 2018.05.30 2017가단32172
기타(금전)
Text

1. The Defendant’s KRW 18,315,00 for the Plaintiff and 6% per annum from April 21, 2017 to May 30, 2018.

Reasons

1. Basic facts

A. On September 22, 2016, the Plaintiff entered into an app Program Development Contract (hereinafter “instant contract”) with the Defendant for the development of three kinds of web-types: (a) on the same day, the Plaintiff paid the Defendant KRW 11,00,000 as down payment.

Contract price: 50,000,000 won (excluding value-added tax): Five times each: 10,000 won - The first payment: the confirmation of planning on September 22, 2016 (within three days from the contract date) - The third payment: the confirmation of design timing (AP) and hub design (AP) - the fourth payment: The fourth payment before the delivery of an Adromode (excluding foreign parent fastening system) - the five payment: The completion of the examination of all outcomes or the customer company server from September 22, 2016 to February 10, 2017 (However, as seen below, the development completion date was extended to March 10, 2017). If the Defendant’s delayed payment is attributable to the cause attributable to the Plaintiff, the compensation for delay shall be paid to the Plaintiff at the rate of 10,000 days delayed due to a cause attributable to the Defendant.

§ 1 (Purpose of Contract) The scope of this service shall be as follows:

1. It shall have the scope of duties not exceeding 45 screens of the C platform standards;

(other than screen pictures of content added by a man, ice pop-up, producer, or manager)

2. The manager's web shall observe the APG manager's day and shall have the scope of duties not exceeding 180 screen pictures;

Provided, That in addition to the Lone Star day, M. A. M. M. M. will take place.

I/UX functions are fully borrowed on the homepage of low convenience function suitable for the purpose of easily dealing with complex managers with which the image of the Masber City is expanded.

(m) Article 2 (Report on Progress and Delivery and Inspection of Results)

1. In a case where the plaintiff and the defendant separately agreed on the schedule for submitting the progress report by phase through prior consultation, the defendant shall report to the plaintiff according to the stage process of project Gap.

At this time, the defendant is designated as agreed with the plaintiff.

arrow