1. The Defendants shall jointly and severally serve as the Plaintiff KRW 187,713,592 and as a result, from September 4, 2012 to September 19, 2017.

1. Basic facts

A. The status of the parties is a company with the purpose of construction business, etc., and the Defendants jointly engage in real estate business.

B. On January 2, 2012, the Plaintiff entered into a construction contract with the Defendants and the E neighborhood living facilities located in Kimpo D (hereinafter “instant building”).

) New Construction Corporation (hereinafter referred to as “the instant construction”)

2) As to the instant contract agreement (hereinafter “instant contract for construction”) and the written contract that was made at the time of the instant contract for construction is “the instant contract for construction.”

The contract was concluded, and its main contents are as follows:

1. Name of official residence: New construction of E neighborhood living facilities;

2. A factory site: Kimpo D

3. Date of arrival: Date of completion of the project on January 2, 2012: KRW 2,112,60,000 (including value-added tax) for the amount of medicinal herbs on June 20, 2012.

8. Quasi-public gold: 11. The rate of liquidated damages for delay shall be 1/1,00 attached documents within one month after the completion of construction works: One copy of the general terms of the contract for private construction works, one copy of the design and calculation sheet (general terms of the contract for private construction works), and the definitions of terms used under such terms and conditions as stipulated in Article 2 (Definitions) shall be as follows:

6. The term “design” means construction specifications, design drawings (including where a bill of quantity is prepared), and site descriptions.

7. The term "bill of quantity" means a detailed statement of items or items constituting the objects by type of work, and the size, quantity, unit, etc. of the same items or items;

8. The term "statement of calculation" means a detailed statement submitted by a contractor to a contractor after stating unit price in a bill of quantity of materials;

Article 3 (Contract Documents) (1) Contract documents shall be composed of contract documents for private construction works, general conditions of contract for private construction works, special conditions of contract for construction works, design documents and calculation sheets, and shall have the effect of mutual supplementation.

Article 16 (Extension of Construction Period) (1) Grounds for the Defendants’ liability or natural disasters, force majeure situations, and supply and demand imbalance of raw materials.