beta
Text
1. Of the judgment of the court of first instance, the part against the defendant exceeding the following amount ordered to be paid shall be revoked.
Reasons
Basic Facts
A. The Defendant received from C Co., Ltd. (hereinafter “C”) a supply of and demand for the installation and dismantling of safety facilities among the construction of new buildings in the multifunctional administrative city E block, and the construction of new buildings in the F block.
B. On March 26, 2014, the Defendant agreed to conclude that “the amount equivalent to 85% of the executing schedule out of the construction price agreed with C” as the construction price for each subcontract when the Defendant subcontracted the construction of safety facilities in the instant block (hereinafter “I”) to the International Stock Company (hereinafter “I”) for all the construction of safety facilities in the said block and the construction of safety facilities in the said E block and the F block (hereinafter “construction 2, 3”, and collectively “the construction in the instant case”).
C. On December 2014, the Plaintiff agreed to receive the work price of I, while accepting the instant construction work from I, and the Defendant also approved it.
Since December 29, 2014, from February 1, 2015 to February 2015, the Plaintiff and the Defendant incurred disputes regarding the construction price and delayed payment of wages. On May 26, 2015, around May 26, 2015, and around July 10, 2015, the first construction was suspended, respectively.
Since then, C directly completed the instant construction project through another company.
[Ground] A without dispute, Gap evidence Nos. 1 through 3, Eul evidence Nos. 48, 49, and 55, testimony of reflection of witness at the trial, fact inquiry conducted by the court of first instance on April 3, 2018 to C, the purport of the whole pleadings, and the plaintiff's assertion as to the plaintiff's claim as to the plaintiff's claim as to the plaintiff's claim as to the construction cost Nos. 762, 517, 760, 756, 485, 210, 764, 652, 452, 22, 3, 861, 361, 360, 361, 000, 848, 761, 760, 860, 842, 810, 813, 425, 252 of Chapter 3 of Chapter 1.
A. As seen in paragraph 4, an accurate calculation of the paid amount that the Plaintiff is a person is 579,278.