1. The Defendants are jointly and severally liable to the Plaintiff for 4,620,000 won and 5% per annum from November 5, 2015 to December 21, 2016.

Basic Facts

Around November 2014, the Plaintiff entered into a construction contract with Defendant B for multi-family houses and newly built works of neighborhood living facilities on the instant land (hereinafter each of the instant construction works, “instant contract”) and the main contents thereof are as follows.

(hereinafter referred to as "special agreement on liquidated damages for delay" and Paragraph (13) of the general terms and conditions of the contract shall be referred to as "special agreement on cancellation of the discontinuance of construction". The standard contract for private construction works

3. Date of commencement: The date scheduled for completion on November 4, 2014: February 25, 2015 (where snow, rain, exceeds 10 days during the construction period and where Han wave (-7°C continued for at least three consecutive days, such period shall be added to the construction period).

5. Contract amount: 1.320,000,000 won are printed in the form of “VAT” in the form of “VAT”, and this part is cut off with several lines, and the seals of both the Plaintiff and Defendant B are affixed to the search line.

6. Contract bond: At least two million won shall be joint and several sureties;

7. Advance: No one; and

8. End payment: 80% of the amount of progress payment within 15 days after the contractor supervises and verifies the claim for the end of the month (20% of the remaining amount shall be paid in full within 45 days after the preservation registration): Contract amount 】 Number of days of delay 】 Number of days of delay / Other matters 2) water supply volume, electricity volume, design and supervision, gas measuring instruments, permission and permission, measurement, industrial accident guard home, employment insurance shall be borne by the project owner (Provided, That this shall not apply to construction completion surveying expenses, and current status surveying expenses).

(4) by January 15, 2015, complete the model house and deliver it to the owner.

General Conditions of Contracts

1. The terms and conditions of this contract are details of a standard contract for private construction works (hereinafter referred to as “standard contract”)’s attached contract, which are agreed upon between the contractor and the contractor, and shall be faithfully implemented in accordance with the good faith principle.

2. Period: From October 1, 2014 to January 31, 2015;

3. The construction contract amount: the amount specified in the standard contract and VAT.