1. Of the judgment of the court of first instance, the part against Defendant B, which exceeds the following amount ordering payment.

1. Basic facts

A. The Plaintiff: (a) the instant training center design service contract between the Plaintiff and Defendant Gakwon Construction; (b) the Plaintiff divided the Plaintiff’s total of eight parcels of land (hereinafter collectively referred to as “instant land”); (c) KRW 43,181 square meters owned by the Plaintiff into “ Incorporated Association I” (hereinafter “instant training center”); and (d) on December 23, 2009, the amount of KRW 222 million between Defendant Gakwon Construction and the instant construction; and (e) from December 23, 2009 to March 31, 2010, the instant construction site into approximately 30,000 square meters of the instant land; and (e) the instant construction site into the instant construction site into the instant 20,000 square meters of the instant land; and (e) the instant construction project site into the instant construction project site into the instant construction project site with the instant construction project site’s total of KRW 30,000 square meters and KRW 15,115,000.

(see, e.g., evidence 34 1-1). (b)

(1) On February 3, 2010, the Plaintiff was changed to the name of Defendant B (E Co., Ltd. at the time of the time of the change to the trade name as of April 30, 2013.

It does not distinguish before and after the change of trade name for the convenience hereinafter referred to as “B”.

B) As between Section B, the ancillary civil engineering works for the primary construction site (hereinafter “the primary construction work of this case”) are as follows: from February 5, 2010 to KRW 1.34 billion for the price and the period;

8.3. Until March, the rate of liquidated damages for delay shall be 1/1.