beta
Text
1. The Plaintiff (Counterclaim Defendant) shall:
A. From September 5, 2015 to December 2017, 2017, KRW 1,551,852,841 and its amount.
Reasons
1. Basic facts
A. The instant construction contract concluding the instant construction contract
6. Construction amount: 6,939,900,000 won (excluding value-added tax);
9. Amount completed of the method of payment of construction expenses: On 10.1 per month: Article 20.(1) of the Terms and Conditions of the Contract for the Construction Work Amount, Article 20.(1)(1) of the Terms and Conditions of the Contract for the Construction Work Amount, Section B [Defendant B] may request an inspection of the completed portion under the contract. In such case, Section A [Plaintiff and F] shall conduct an inspection without delay and notify the results to Section B, and if no notification has been made within 14 days, the inspection shall be deemed to have passed.
(3) A shall pay B the completed amount according to the details of the inspection within 15 days from the date of completion of the inspection.
Article 25 (Compensation for Delay) (1) When the construction work within the deadline for completion has not been completed, the amount calculated by multiplying the contract price by the delayed rate in the contract shall be paid to the Party A for each number of days immediately.
Provided, That where a Party A deems that the construction has been delayed due to any of the following causes, Party B need not pay the penalty for delay equivalent to the relevant number of days:
3. Where the commencement of construction has been delayed or suspended due to causes attributable to Party A;
4. Other matters entered into a special agreement where any construction work is delayed due to any cause not attributable to B.
1. The trial corporation shall complete the responsibility;
9. Monthly payments and financial right loans shall be made for monthly payments;
10. If the construction cost is not paid, it shall be paid as loans or rental deposits within two months after the completion, and if it is not performed, it shall be adjusted to the contractor by 50% of the face-to-door sales amount of officetels.
1) The Plaintiff, which is the Plaintiff’s owner, shall newly construct the instant building (a 8-story officetel) on the instant land (U.S. E. 934.7 square meters), and omitted the entry of the “stock company” for the remaining companies on July 27, 2011.
jointly with the defendant.