1. The Defendant shall pay to the Plaintiff KRW 1,182,894,891 among the Plaintiff and KRW 1,176,48,431 from March 1, 2015.

1. Basic facts

A. On May 2012, the Defendant entered into a contract for a construction project, which was awarded a contract for “B” (hereinafter “the entire construction project of this case”) from Korea Southern Development Co., Ltd.

B. 1) On May 2, 2013, the Plaintiff entered into a subcontract and a modified contract with the Defendant, as well as the construction of soil and structures among the entire instant construction works that the Defendant received as a contract (hereinafter “instant existing construction works”).

(2) The Plaintiff and the Defendant concluded the first modified contract, which extended the construction completion date on November 18, 2013 to January 31, 2015, which extended the construction completion date on January 31, 2015, the second modified contract, which increases the construction amount of KRW 15,31,771,400, which increases the construction amount of KRW 15,589,530,000, and which increases the construction amount of KRW 15,589,530,00 on June 16, 2014, respectively.

(3) The main contents of the instant contract for construction are as follows (A shall be the defendant, and B shall be the plaintiff). Article 13 (Unconformityd Construction Works) of the General Conditions for the Subcontract of Construction Works (A shall be deemed as follows:

(2) The adjustment of a contract price under paragraph (1) shall be governed by the following standards:

(b).