The plaintiff's claim is dismissed.

Litigation costs shall be borne by the plaintiff.

1. Basic facts

A. From April 2017, the Plaintiff started the construction work to set the canal wells to the land of the G and D (hereinafter “Plaintiff’s land”).

B. On August 3, 2017, the Defendant obtained the ownership of Yeongdeungpo-gu E (hereinafter “Defendant’s land”) adjacent to the Plaintiff’s land (hereinafter “Defendant’s land”); and on August 11, 2017, the Defendant obtained permission from the Young-gu mayor to establish neighboring facilities and multi-family housing on the Defendant’s land (hereinafter “Defendant Corporation”).

From October 2017, the defendant started the defendant construction work.

C. Around November 2017, among the Dos where the Defendant Corporation was proceeding with the discontinuance of the Plaintiff’s construction work, the floor of the Plaintiff’s land was laid down. Accordingly, the Plaintiff suspended construction around December 8, 2017.

On March 7, 2018, F Co., Ltd. completed the registration of the right to claim ownership transfer on the Defendant’s land, the Defendant completed the registration of the right to claim ownership transfer on March 7, 2018 on the Defendant’s land.

(No. 1) and (e)

On April 12, 2018, G of the instant arrangement 1F representative director G: (i) the Plaintiff, among the Defendant’s construction works, caused problems, such as h-sn beam excavation and the alteration of earth and sand structures due to earth pressure due to the failure to complete earth and sand installation works; (ii) there is no objection in the event of collapse, etc. to the Plaintiff due to the instability in the present construction work; (iii) if the part of the Defendant’s construction works already executed exceeds the site boundary, the reinforcement work is performed; and (iv) if the Plaintiff’s measure is not raised against the Plaintiff’s measure; and (v) if the construction work is not performed, the construction work schedule is consulted with the construction work company and the construction work schedule, and the construction work schedule is notified.

4. Removal of temporary facilities by up to 30. The soil mounds installed on the Defendant’s land; and

“,” has drawn up a letter of performance assurance.

(A) No. 11, thereafter.