1. The Defendant (Counterclaim Plaintiff) is jointly and severally liable to the Plaintiff (Counterclaim Defendant) for KRW 5,871,020 and its amount from December 1, 2014 to December 1, 2016.

A principal lawsuit and a counterclaim shall be deemed simultaneously.

1. Facts of recognition;

A. The Defendants are co-contractors of the B improvement project ordered by the Gyeonggi-do Construction Headquarters (hereinafter “instant project”). The ratio of shares is 51% for the Defendant Co., Ltd. (hereinafter “Defendant”) and 20% for the Defendant Co., Ltd. (hereinafter “Co., Ltd.” in the name of each Co., Ltd.), 29% for the Defendant Jin Industry, and 20% for the Defendant Geum River General Construction.

General Conditions of Estimated

1. The terms and conditions of this estimate of the definitions of the terms are for the instant project agreement, and are for the Defendant, the original beneficiary, and the lower beneficiary, “A”.

3. Where documents are placed in order of priority and there are different opinions, the priority order shall be as follows:

(i)The site descriptions (the on-site explanation conditions, the general conditions for estimates, and special conditions for estimates) 2) specifications 3) specifications, 5) General terms and conditions of the subcontract agreement 6) and other documents, provided that the priority order is specified for less than 2) in the contract documents on the ordering place, if any, in accordance with the terms and conditions of the ordering place.

6. 1) Section B, upon site site entry, should complete the construction work in the contract air proposed by A.

However, in the event that the air has been extended due to reasons not attributable to Eul, if the additional costs incurred in the extension of the air have been settled by the owner of the air from the owner, the relevant costs shall be paid to Eul in proportion to the contents and proportion thereof, and it shall not be required to pay Eul if not paid by the owner of the construction

C) If Party A considers that it is delaying the planning process, Party B may request Party B to submit a written notification of this fact to Party B, and Party B shall immediately submit a plan to meet the delay process and take all necessary measures for the delay process only. Party B shall bear all the additional costs incurred in relation to the delay delay delay delay meetings for not less than one month compared to the originally planned process.