1. The plaintiff's claim is dismissed.

2. The costs of lawsuit shall be borne by the Plaintiff.

1. The judgment as to the cause of the claim was made on March 4, 2013 with the Defendant and the construction cost of KRW 60 million for an urban-type residential housing construction project (hereinafter “instant construction project”). During construction, the Plaintiff entered into a construction contract with the Defendant by setting the construction cost of KRW 31,920,00,000, and delayed for six months or more than the time the construction was completed originally scheduled due to the Defendant’s voluntary suspension of construction while performing the construction work. Unlike the construction of parking lot non-construction, rooftop and stairs room, the Plaintiff directly cut the rooftop roof and cut the Plaintiff’s waste disposal expenses, cutting the Plaintiff’s waste disposal expenses, cutting, reconstruction expenses, removal expenses, removal expenses, and removal expenses used by the Defendant, and the completion of construction, the Plaintiff’s defect in the construction project, as alleged by the Plaintiff, was alleged by the evidence that the Plaintiff incurred the Plaintiff or the Plaintiff’s defect in the construction project.

In addition, it is insufficient to recognize that the delay in the construction of this case caused damage to the amount claimed by the Plaintiff, and there is no other evidence to prove the Plaintiff’s assertion.

Therefore, the plaintiff's claim is rejected.

2. In conclusion, the plaintiff's claim of this case is dismissed as it is without merit. It is so decided as per Disposition.