1. The Plaintiff (Counterclaim Defendant) shall pay to the Defendant (Counterclaim Plaintiff) the full amount of KRW 97,696,742 as well as the full payment from October 18, 2013.

. It shall be 12 months or 24 months;

Provided, That in the case of wood materials, natural phenomena (e.g., reg., g., reg., reg., reg.) shall not be responsible.

(2) "B" shall repair all defects incurred in the relevant construction during the period of liability for defects prescribed in the contract from the date on which the whole subject matter of the contract is acquired and the completion date of the inspection of completion is completed.

Provided, That the same shall not apply where a cause, such as a natural disaster, occurs after the delivery of the object of the construction, or a cause not attributable to "B".

[Matters of Special Agreement]

1. 460,00 won for 12 persons, such as luminous emitting ices (cash) 8,040,000 won (2) Electric luminous emitting ions (LG) iones (LG) 1,050,000 won (3) Borrowing stacks (LG) 12 persons;

2. Living rooms of the first floor (LG) 15,000,000 won. (1) Living rooms of the second floor (2) Living rooms of the second floor;

3. Installation of fences and gates 10,000,000 won;

4. Ceropic products of KRW 10,000,000 on a wall or column;

5. Zertoves (GASS and Electricity) 15,000,00 won* The above contents are included in the aggregate amount of construction, and “B” shall use all the products after obtaining approval from “A”.

B. Meanwhile, on May 31, 201, prior to the conclusion of the instant construction contract, the Plaintiff received a design map of the total floor area of 230.94 square meters from the D architect design office designated by the Defendant, and the said design drawing was the same year.

6. Until December 29, 200, the total floor area was increased to 256.56 square meters as a result of the change at the request of the Plaintiff or the Defendant twice.

C. Following the process of the instant construction project, the Defendant paid KRW 298.4 million to the Plaintiff by November 201, 201. However, around that time, conflicts between the Plaintiff and the Defendant with respect to additional construction cost and delay of construction, etc., and the said construction was suspended.

On December 29, 2011, the Defendant requires the Plaintiff to complete the instant construction work as soon as possible by expressing his/her opinion on the complaints and additional construction cost for delay.