1. The Defendant’s KRW 79,879,187 as well as the Plaintiff’s annual rate from July 4, 2013 to November 30, 2017, and the following.

1. Basic facts

A. The Plaintiff is a company with the objective of manufacturing new and renewable energy machinery and designing and designing new and renewable energy machinery, and the Defendant is the owner of the area of 2,832 square meters in Jung-Eup City.

B. Around October 2012, the Plaintiff entered into the instant contract and paid part of the purchase price (i) with the Defendant, as the construction cost of KRW 650,000,000 (excluding value-added tax) and the scheduled date for completion of the instant contract, determined on February 2, 2013, the Plaintiff shall be subject to DNA solar power plant (hereinafter referred to as “instant power plant”) on the ground of 2,832m2 square meters in Jung-Eup-

) A solar power plant construction contract to newly construct a solar power plant (hereinafter referred to as “instant contract”).

(2) The Plaintiff received, respectively, KRW 50,00,000 on November 12, 2012 as the construction cost under the instant contract from the Defendant, KRW 100,000 on January 9, 2013, KRW 100,000 on January 23, 2013, KRW 200,000 on January 24, 2013, KRW 50,000 on February 20, 2013, KRW 50,000 on February 20, 2013, and KRW 50,000 on April 19, 2013, and KRW 50,000 on July 30, 2013, respectively.

3) On February 13, 2013, the Plaintiff issued a tax invoice of KRW 650,000,000 for the supply price for solar construction work to the Defendant. (c) On February 2, 2013, the Plaintiff completed the instant construction work under the instant contract (hereinafter “instant construction work”).

2) On February 7, 2013, the Defendant entered into an agreement on the supply and demand of electric power plants and an agreement on the parallel driving operation with the Korea Electric Power Corporation to supply and demand electric power capacity of 300 kws. 3) On February 8, 2013, the Defendant received a prior inspection from the Korea Electric Safety Corporation on the electric power generation facilities (22,90V, 300 kw) of the instant electric power plant from the Korea Electric Safety Corporation and received a certificate of confirmation prior to the use of the judgment. On February 12, 2013, the Defendant reported the commencement of operation of the instant electric power plant to the Governor of Jeollabuk-do.

4) On June 10, 2013, the Defendant obtained a license for the electric power generation business from the Governor of Jeollabuk-do to the instant electric power plant. [Grounds for recognition] Facts that there is no dispute, and evidence Nos. 1 through 5, 9, and 15 (including the serial number; hereinafter the same shall apply)

....