1. The Defendant’s KRW 29,785,394 for the Plaintiff and KRW 5% per annum from July 8, 2015 to August 25, 2016.

1. Basic facts

A. On March 12, 2014, the Plaintiff entered into the following construction contract (hereinafter “instant contract”) with the content of the construction of the building project (hereinafter “instant construction project”) consisting of the Plaintiff and the Defendant and the Cheongbuk-gun B and the 2 multi-household housing unit (A Dong, B Dong, and hereinafter the above two Dongs collectively referred to as “instant building”).

Standard contract for private construction works

1. Name of the construction project: New construction of a D senior household;

3. Date of commencement: At the time of commencement on March 20, 2014 (at the time of commencement submission).

4. Date scheduled for completion: October 20, 2014.

5. Contract amount: 11. The rate of liquidated damages: 1/1,000,000: the date of commencement and completion of construction work shall be the date specified in the contract.

(2) Where it is impossible to start the commencement date of construction without any cause attributable to the defendant, the date of commencement shall be the date of commencement, and in such cases, the defendant may request extension of the construction

③ The date of completion refers to the date the Defendant completed construction works and requested the Plaintiff to undergo a completion inspection in writing.

Provided, That this shall be limited to the cases of passing a completion inspection under Article 27.

Article 27 (Completion Inspection) (1) The defendant shall notify the plaintiff upon completion of construction, and the plaintiff shall conduct the inspection without delay in the presence of the defendant after receiving the notification, and if the plaintiff fails to notify the result of inspection within ten days after receiving the notification of the defendant, the inspection shall be deemed to have passed at the expiration of ten days.

Article 30 (Compensation for Delay) (1) When the defendant fails to complete construction within the construction period, he shall pay to the plaintiff an amount calculated by multiplying the contract amount by the rate for delay in the contract by the number of days delayed.

Provided, That where a completion inspection has been delayed due to a cause attributable to the plaintiff and where the construction has been delayed due to any of the following causes, the compensation for delay corresponding to the number of relevant days shall be paid: