1. The Defendant-Counterclaim Plaintiff (Counterclaim Defendant) amounting to KRW 160,000,000 for each of the Plaintiff-Counterclaim Defendant and its related amount from April 12, 2018 to April 202.

1. Basic facts

A. On July 29, 2014, the Plaintiffs entered into a construction contract with the Defendant to newly construct 16 units of multi-household houses on the land owned by the Plaintiffs (hereinafter “instant construction contract”) and on December 15, 2014, respectively, on the following grounds: (a) the construction contract for the construction of new factories on the land owned by the Plaintiffs, Youngcheon-si, Youngcheon-si, the Plaintiffs owned by the Plaintiffs; (b) the construction of new multi-household units (hereinafter “instant construction work”; and (c) the construction of the instant construction of new factory building (hereinafter “instant GG”) and the outline of its construction is as follows.

Standard contract for private construction works (this case FIG)

1. Construction name: H building I and multi-household new construction works in J-dong;

2. Period for construction: The contract amount on August 21, 2014 and February 3, 2015: 1,415,040,000 won (including value-added tax) for the scheduled completion of construction works on February 28, 2015.

4. The rate of liquidated damages for delay: 1/100 shall be the date specified in the contract, respectively.

(2) Where it is impossible to start the commencement date of construction without any cause attributable to the defendant, the date of commencement shall be the date of commencement, and in such cases, the defendant may request extension of the construction

(3) The completion date refers to the date the defendant completes construction works and requests the plaintiffs to undergo a completion inspection in writing.

Provided, That this shall be limited to the cases of passing a completion inspection under Article 24.

Article 25 (Payment of Price) (1) After passing the inspection on the completion of construction, the Defendant may adjust the construction site, such as the removal or removal of surplus materials, wastes, temporary facilities, etc., and claim the payment of the construction price to the Plaintiffs.

(2) The plaintiffs shall pay the price for the construction to the defendant simultaneously with the delivery of the object of the contract, unless otherwise stipulated.

Article 27 (Compensation for Delay) (1) When the defendant fails to complete construction works within the deadline for completion, the amount shall be not more than the amount calculated by multiplying the contract price by the rate for delay in the contract for each day of delay.