beta
(영문) 수원지방법원안산지원 2014.09.25 2013가합22475

지체상금

Text

1. The plaintiff's claim is dismissed.

2. The costs of lawsuit shall be borne by the Plaintiff.

Reasons

(b) the facts of the basis;

A. On November 12, 2010, the Plaintiff (contractor) and the Defendant (contractor) concluded a contract for construction works (hereinafter “instant contract”) with the following content.

(c) The name of the sound construction: The date of commencement of the construction work of the building of the building of the building of the building of the Dosan City in Jeollabuk-do on November 17, 201: the contract amount on August 30, 201: 3,107,500,000 won (the supply price of KRW 2,825,00,000, value-added tax 282,500,000): The advance payment under the condition that no contract bond exists: The attached rate of liquidated damages for delay attached to the attached Form 1/1,000: Article 3 (the scope of construction works) of the Special Clause (the scope of construction works).

1. Construction 2) Construction Work 2) Construction Work * Construction 3) Construction in accordance with structural drawings * Construction Work 25,00,000,500,500,000 (in the event of a contract for the original cost-added tax (in the event of a payment condition and timing of construction cost) construction) in accordance with structural drawings ? Construction Work 25,00,000,500,000 (in the middle omission) and 1,40,000,000,000 total amount of 2,825,000,000,000,002,282,50,000,000 (special engineer 1), “B” under Article 6 of the contract shall be paid to “A” by no later than 13, 2010, in accordance with the drawings paid by “A.”

Article 1 (General Provisions) A (hereinafter referred to as "A") and the contractor (hereinafter referred to as "B") of the General Conditions of the Contract for Construction Works shall comply with the contract in good faith in cooperation with each other on an equal basis.

Article 27 (Compensation for Delay) (1) When construction work is not completed within the deadline for completion, "B" shall pay to "A" the amount calculated by multiplying the contract price by the rate of the compensation for delay in the contract (hereinafter referred to as "compensation for delay") for each number of days immediately.

Provided, That where a completion inspection has been delayed due to a cause attributable to A, and where construction has been delayed due to any of the following causes, compensation for delay equivalent to the number of relevant days need not be paid:

3. Commencement on the grounds attributable to “A”