beta
(영문) 춘천지방법원강릉지원 2015.12.22 2014가합101067

공사대금

Text

1. The Defendant’s KRW 133,529,010 and the Plaintiff’s annual rate of KRW 6% from October 11, 2014 to December 22, 2015.

Reasons

1. Basic facts

A. On March 4, 2013, the Plaintiff was awarded a contract by setting the contract amount of KRW 840 million for the construction of the Defendant’s business facilities on the ground (hereinafter “instant construction works”) from the Defendant on the ground of Gangnam-si (hereinafter “instant construction works”), from March 6, 2013 to December 31, 2013, with the construction period of KRW 1/100 per the number of delayed delay delay delay penalty, as the contract amount of KRW 840,000 for the construction work period (excluding value-added tax).

(hereinafter “the instant construction contract”). The construction content and the construction amount agreed upon at the time of the instant construction contract are KRW 136,069,641; KRW 329,296,04; KRW 329,294; electricity, telecommunication; electricity, telecommunication; KRW 135,726,913; KRW 163,627,131; KRW 75,280,271.

(Attachment 1 Construction Contract Nos. 1 through 5 and contract amount in the attached Table 1 Construction Contract Table). (b)

On the other hand, the general terms and conditions of the private construction contract included in the instant construction contract include the following:

Article 9 [Period of Construction] (1) The date of commencement and completion of construction work shall be the date specified in the contract.

(3) The completion date means the date when Eul completed construction works and a written request for a completion inspection is made to Gap.

However, it shall be limited to the cases of passing a completion inspection under Article 24.

Article 13 [Safety Control and Accident Compensation] (1) B shall take appropriate measures, such as the installation of safety facilities and subscription to insurance, to prevent industrial accidents, and for this purpose, A shall include the amount equivalent to the safety control expenses and the industrial accident compensation insurance fees in the contract amount.

Article 14 (Protection of Construction Workers) (2) A shall appropriate the installments for the retirement pension system for construction workers, the employer contributions and employment insurance premiums under the wage claim guarantee system under paragraph (1) in the contract price.

Article 24 [Completion Inspection] (1) “A” shall be notified to A when the work is completed, and “A” shall conduct the inspection without delay in the presence of “B” after receiving the notification, and if “A” fails to notify the results of the inspection within 10 days after receiving the notification of “B”.