공사대금
1. Of the judgment of the first instance court, the part against the defendant in excess of the following amount ordered to be paid shall be revoked and this shall apply.
1. Basic facts
A. On December 2017, the Defendant agreed on December 1, 2017 to request the Plaintiff to make an estimate of the interior works of the instant restaurant (hereinafter “instant restaurant”). On December 11, 201 of the same year, the Defendant: (a) provided a quotation and design drawings from the Plaintiff; and (b) agreed on December 14, 201 to change the final construction cost to KRW 53 million by adding a estimate and a design drawing from the Plaintiff; and (c) to the Plaintiff, the Defendant agreed on December 14, 2017 to change the final construction cost to KRW 53 million.
B. On December 14, 2017, the Plaintiff of the Plaintiff’s design and removal construction work offered design and design by changing the design and design to the Defendant several times from around December 14, 2017 to around February 28, 2017 at the Defendant’s request, and completed consultations with the Defendant on the design design design design and the design design design design design and the thirdD image on December 28, 2017, and notified the Defendant of the schedule for the removal construction on December 29, 2017, and completed the removal construction at the instant restaurant on December 29, 2017.
(c)
Notification of Suspension of Works by the Defendant