beta
(영문) 부산지방법원 2018.10.23 2017가단23369

손해배상(기)

Text

1. Defendant Taewon Construction Co., Ltd. shall pay to the Plaintiff KRW 93 million and its full payment from August 23, 2017.

Reasons

1. Basic facts

A. On March 2, 2016, the Plaintiff contracted to Defendant Taewon Integrated Construction Co., Ltd. (hereinafter “Defendant Co., Ltd.”) for the construction of the instant multi-household building (hereinafter “instant construction”). The main content of the construction contract is as follows.

Construction cost: 1.344 billion won: From March 2, 2016 to July 30, 2016: 1/1000 in cases of liquidated damages:

나. 피고 회사는 2016. 6. 15. 피고 B(상호: D)에게 이 사건 공사 중 샷시공사 부분을 공사대금 1억 3,500만 원(부가가치세 포함 1억 4,850만 원), 공사기간 2016. 6. 15.부터(공사완료일은 정하지 아니함)로 정하여 하도급하였는데, 특약사항으로 '50% 기성으로 하고 나머지 금액은 준공 후 분양 지급'이라고 기재하였다.

다. 피고 B은 공사대금 중 일부금으로 2016. 7. 27. 1,500만 원, 2016. 8. 26. 4,500만 원 및 2017. 2. 16. 750만 원을 각 지급받은 후 2017. 4. 30.경 위 샷시공사를 완료하였다. 라.

The Defendant Company completed the instant construction work on June 13, 2017, and received the payment of the construction cost of KRW 1.34 billion from the Plaintiff on June 30, 2017.

[Ground of recognition] Facts without dispute, Gap evidence Nos. 3 through 6, Eul evidence No. 1, the purport of the whole pleadings

2. According to the facts of the determination as to the claim against the defendant company, the defendant company is obligated to pay to the plaintiff the total amount of KRW 427,316,00 (= KRW 1,348,00,000 x 317 x the plaintiff is liable for delay from the completion date under the construction contract of this case. However, the plaintiff is liable for delay from July 31, 2016, which is the day following the completion date to June 13, 2017, which is the completion date of construction x 1/1,000 x 1/1,000 x 93 million within the scope the plaintiff seeks and the copy of the complaint of this case from August 23, 2017 to the day after the completion date of construction x 15% per annum under the Act on Special Cases concerning the Promotion, etc. of Legal Proceedings.

Defendant Company.