손해배상(기)
1. The Defendant (Counterclaim Plaintiff) paid KRW 23,226,00 to the Plaintiff (Counterclaim Defendant) for KRW 23,226,00 and for this, from September 2, 2014 to May 12, 2016.
A principal lawsuit and a counterclaim shall be deemed simultaneously.
Basic Facts
The plaintiff is a person who runs a private business in the name of B, and the defendant is a company that runs a building business.
On August 13, 2013, the Plaintiff entered into a building construction contract (hereinafter “instant construction contract”) with the Defendant, setting the construction cost of KRW 8,300,000 (including value-added tax; hereinafter the same shall apply), August 13, 2013, and February 28, 2014, with respect to the construction work of Seongbuk-gu Seoul Metropolitan Government Ground Living Facilities (hereinafter “instant building”) (hereinafter “instant construction work”). The main contents are as follows.
The instant construction contract
1. Construction name: New construction works of D neighborhood living facilities;
2. Location of a site: Seongbuk-gu C;
3. Period: Amount of contract on August 13, 2013 to February 4, 2014: 803,000,000 won: Value-added tax amount of KRW 730,00,000: 73,000,000.
5. 10% of 1 down payment (time of commencement) per annum (excluding value-added tax) 73,000,0002 10% of 73,000,000 36,500,000 30,000 36,500,0004 36,50,0004 36,50,50,000 0,005 0,005,4 05,4 05, 005, 005, 005,005, 005, 30,000, 00, 000, 00, 00, 005, 30,00,000, 05, 36,05,00,000, 5,00,06,06,05,05,000 other than 3,06,06,06,00
7. Rate of liquidated damages: 0.2% of the contract amount per every number of days delayed from the day following the contract term.
8. Other matters: The plaintiff and the defendant conclude a contract of construction in accordance with this contract and the separate design drawings and specifications, and prepare two copies of this contract and related documents as evidence, and keep each copy of them.
Article 13 (Extension of Work Period) (1) The plaintiff's responsible reasons.