보증금반환
1. The Defendant’s KRW 3,993,00 to the Plaintiffs, as well as 6% per annum from October 19, 2019 to November 12, 2020, respectively.
1. Basic facts
A. On January 10, 2018, the Plaintiffs concluded a contract with D (hereinafter referred to as “D”) for the construction of a new building on the ground of the Busan East-gu E (hereinafter referred to as “instant construction”) with the contract amount of KRW 990,00,000 (including value-added tax) and the construction period from January 16, 2018 to April 30, 2018.
(hereinafter “instant construction contract”). B.
As of January 10, 2018 to April 30, 2018, the Defendant entered into a contract guarantee agreement with D to pay the Plaintiffs the actual amount of damages arising therefrom within the scope of the guaranteed amount (hereinafter “instant guarantee agreement”) and issued a guarantee certificate to the Plaintiffs on January 17, 2018. < Amended by Act No. 15004, Jan. 17, 2018>
C. D’s commencement of the instant construction on January 16, 2018, and continued the instant construction on September 11, 2018 when most of the structural construction was completed.
The Plaintiffs, on October 10, 2018, notified D that the instant construction contract was cancelled on April 30, 2018, while 160 days were delayed compared to April 30, 2018, when D requested the payment of unfair additional construction cost, delayed the progress of construction, and completed the instant construction work.
E. On October 23, 2018, the Plaintiffs entered into a contract for construction works with F Co., Ltd. (hereinafter “F”) under which the instant construction works were contracted with the construction cost of KRW 748,00,000 (including value-added tax) and from November 10, 2018 to March 10, 2019. Since then, the said contract was finally increased over twice, and the said construction cost was finally changed to KRW 76,953,00 (including value-added tax).
(f) The Plaintiffs: (a) KRW 70,00,00 on November 22, 2018; (b) KRW 168,750,00 on December 18, 2018; and (c) KRW 194,10,000 on January 15, 2019; (b) KRW 13,00,000 on August 1, 2019; and (c) KRW 20,00,000 on August 1, 2019; (d) KRW 5,00,000,000 on February 28, 2019; and (e) KRW 194,100,000 on July 1, 2019;