beta
(영문) 수원지방법원 2020.05.20 2019나67708

공사대금

Text

1. Of the judgment of the court of first instance, the part against the defendant exceeding the amount ordered to be paid below shall be revoked.

Reasons

1. The reasons for this part of the basic facts are as follows: (a) the second 14th 14th tier of the judgment of the court of first instance, “this case’s Pyeongtaek and Yang Pyeong Corporation is currently completed at present” is the same as the part of “1. Basic Facts” in the judgment of the court of first instance, except that “if two construction works are jointly referred to, it is currently completed at present.” (hereinafter “each construction works of this case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case’s case.

3. Judgment on the defendant's defense

A. The gist of the Defendant’s assertion 1) The Plaintiff’s defense of offsetting the claim for liquidated damages was suspended in the absence of completion of each of the instant construction works. The Defendant completed the remainder construction work on August 26, 2017, and the mass construction work on June 29, 2017. Accordingly, when calculating liquidated damages according to the rate of liquidated damages for the number of delayed days prescribed in each of the instant construction contracts, the Defendant’s compensation for delay is calculated based on the rate of liquidated damages for the number of delayed days prescribed in each of the instant construction contracts, the amount of KRW 77,760,00 (i.e., the construction cost of KRW 240,00,000 x the rate of liquidated damages x 0.3% x the number of delayed delay x 3,630,000 won (i.e., the construction price of KRW 222,000 x 0.3% x 55 days in lieu of the rate of liquidated damages x the Plaintiff’s claim for offset against the defect repair damages.