양수금
1. The part concerning the principal suit in the judgment of the first instance, including the claims modified and added by this court, is as follows.
1. The reasoning for the court’s explanation on this part of the basic facts is as follows, and this part of the judgment of the court of first instance is identical to that of “1. Facts recognized” under the main sentence of Article 420 of the Civil Procedure Act. As such, this part is cited.
Under 2, "A apartment (hereinafter referred to as "the apartment of this case")" of 4 to 5 - is "the apartment of this case" as follows:
Defendant consisting of the representatives of the occupants;
B. A construction work to convert “a construction work to be converted” under two (2) as follows (hereinafter “instant construction work”).
C. The 3rd MM “K” was amended by the Korea Development Bank, Inc. (hereinafter “KM”) as follows:
D. The Defendant (a party to a contract was also involved in the management office) and the large energy entered into a modified contract on October 31, 2012, which extended the construction period on November 30, 2012, to the extent that the period of construction was extended by November 30, 2012.
However, the instant construction project had been delayed until March 15, 2013, and the large energy had been demanded to the Defendant to compensate for damages incurred due to the delay in construction, and the Defendant (the management office also participated as a party to the modified contract) and the large energy had changed the construction period from September 25, 2012 to March 15, 2013 to the construction period from March 15, 2013, and the construction price was KRW 277,00,000 (excluding value-added tax) and the date of preparation of the contract was retroactively stated on October 2, 2012.
E. Under 4, from the 7th day to the 4th day, “transfer,” 5th day to the 5th day to the 5th day to the instant transfer (hereinafter “transfer of claims”).
G. On September 4, 2013, the Plaintiff and Dae Young Energy jointly transferred the sales claim under the contract form signed on November 7, 2012 to Dae Young Energy.