A. On February 16, 2015, C, on behalf of the Plaintiff, entered into a contract with the Defendant for the following (hereinafter “instant contract”) on behalf of the Plaintiff: (a) the construction of the rest of an officetel building, the structural frame of which was completed by the Plaintiff’s ground frame D, such as tide, strawing, outer walls (ston), interior strawing, mooring, fishing, painting, and painting, on behalf of the Plaintiff; and (b) the construction of which is completed:

1) The date of commencement of construction cost of KRW 220,00,000 for advance payment of KRW 80,000 for advance payment of KRW 70,00 for intermediate payment, KRW 70,000 for intermediate payment, and KRW 70,000 for remainder payment, KRW 70,000 for remainder payment, and KRW 20,00 for remainder payment of KRW 30 on February 17, 2015; KRW 1/1,000 for delay payment interest rate of KRW 1/1,00 for delay interest rate (construction amount) and KRW 5) for electrical entry, water supply volume, communication, CCTV, and fire fighting construction separate consultation (excluding value-added tax) on charges for securing independent space of KRW 10,00 for each floor and interest rate of KRW 2.5% for each month after consultation on external materials to the owner of the building.

B. During the foregoing construction, the Defendant: (a) performed the construction of sculptures and windows (90%) following the interior structural change; (b) 90% of the unused waterproof construction; (c) part of the electrical construction; and (d) the installation of a new strawing construction; (b) was legally detained on May 14, 2015 while performing the external strawing construction; and (c) at the time, the height height rate was 45%.

C. On May 15, 2015, the Plaintiff employed E as a field manager, and entered into a contract with the Defendant directly or with the new company during that process with respect to the remainder of the construction [10% of the waterproofed Construction Work, external metric tons Construction Work, the rest of the toilet sculptures Construction Work, the installation of toilets, the installation of toilets, the installation of toilets, the installation of toilets, the installation of toilets, the installation of toilets, the installation of a boiler, the installation of a boiler, the installation of a boiler, the installation of a boiler, the installation of a boiler, the installation of a boiler, the water supply, the boiler construction, the elevator construction, etc.].

The plaintiff's use on May 29, 2015.