손해배상(기)
1. The plaintiff's claim is dismissed.
2. The costs of lawsuit shall be borne by the Plaintiff.
1. Basic facts
가. 원고는 C과 제주시 D 소재 ‘E 제주 협재 점’( 이하 ‘ 이 사건 가맹점’ 이라 한다) 의 가맹사업계약을 체결하고, 2016. 12. 20. 이 사건 가맹점의 인테리어 공사( 이하 ‘ 이 사건 공사’ 라 한다 )를 공사금액 185,000,000원, 공사기간 2017. 2. 8. ∽2017. 3. 24. 로 정하여 원고가 시공하는 계약을 체결하였다.
나. 원고는 2017. 2. 경 피고에게 이 사건 공사를 공사대금 175,000,000원, 공사기간 2017. 2. 2. ∽2017. 3. 25. 로 정하여 도급( 이하 ‘ 이 사건 공사계약’ 이라 한다) 주었다.
(c)
On June 1, 2017, C filed a lawsuit against the Plaintiff seeking payment of KRW 35,493,600,000 as a result of delay in the instant construction project, and KRW 30,000,00 as a loan to the Plaintiff (No. 60804, Jeju District Court 2017) in lieu of the compensation for delay due to delay in the instant construction project, and KRW 30,00,00 as a loan to the Plaintiff (No. 60804, Jeju District Court 2017).
(d)
After the filing of the lawsuit, on December 6, 2017, the Plaintiff and C agreed that “The Plaintiff shall pay C the amount of KRW 25,000,000 and the amount of KRW 30,000 borrowed by the Plaintiff as compensation for delay and defects related to the instant construction,” and C withdrawn the said lawsuit.
[Ground for recognition] Unsatisfy, Gap 1 to 3 statements (including various numbers; hereinafter the same shall apply), the purport of the whole pleadings
2. Judgment on the plaintiff's assertion
A. The alleged defendant delayed the construction of the instant case and caused a delay in the award, and the plaintiff agreed with C and C to determine the amount of the delayed award as KRW 25,00,000, and paid the said amount to C, so the defendant shall pay the amount of the delayed award to the plaintiff.
Since the Plaintiff borrowed KRW 30,00,000 from C again to the Defendant, the Plaintiff sought the return of the above loan.
Even after the completion of the instant construction project, the Plaintiff incurred expenses of KRW 5,150,500.